COVID-19 Delays May Warrant Additional Time But Not Additional Costs
A recent decision issued by the Civilian Board of Contract Appeals (CBCA) could offer some insight as to how courts will treat the inevitable flood of COVID-19 delay claims that will soon surface. The decision stems from a case where an outbreak of Ebola disrupted a government contractor constructing a rainwater capture and storage system in Western Africa. Despite the World Health Organization declaring an “international public health emergency” the U.S. Department of State opted not to cease its operations. However, the contractor subsequently made the decision to temporarily de-mobilize and evacuate its employees from the area. Six months later the contractor returned to complete the project while providing basic medical facilities and services on the project site to ensure the safety of its workers. After the government denied the contractor’s request for an equitable adjustment for demobilization and medical expenses, the contractor appealed the decision through the CBCA.
In granting the government’s Motion for Summary Judgment, the CBCA held that the contract’s excusable delay provision (the equivalent of a force majeure clause) provided the contractor the right to additional time but not additional costs. In reaching its decision, the CBCA reasoned that the government never changed the nature of the work contracted for and likewise never instructed the contractor to demobilize or provide additional life safety measures.
While the circumstances faced by most contractors in our current crisis differ considerably from those detailed here, the CBCA’s ruling does provide some useful information on what contractors can expect in future COVID-19 disputes. Indeed, while many have been focusing on force majeure provisions to determine their liability for delays and increased costs, in most contracts including AIA A-201-2017, these provisions only provide relief in the form of additional time, not additional costs. In determining whether increased general conditions are recoverable, it will often be necessary to look past force majeure provisions in favor of language relating to suspension or termination of the project.
When a project is terminated or suspended by the owner though no fault of the contractor or otherwise terminated by the contractor due to “an act of the government” many standardized contracts provide contractors the right to recover the costs of the work completed, plus overhead and profit for the work they would have completed. Similarly, many standardized contracts provide contractors with similar payment rights when an owner breaches its duty to provide access to the site or to